Terms & Conditions

TERMS AND CONDITIONS

Last updated: 30 April 2026

AGREEMENT TO OUR LEGAL TERMS

We are AirPlus Renewables Ltd (AirPlus Renewables, Company, we, us or our).

We operate the website https://airplusrenewables.com (the Site) and may provide related products, services, content, enquiries, quotations, technical information, distributor information, support documents and other services that refer or link to these Terms (together, the Services).

You can contact us by email at info@airplusrenewables.com or by post at:

These Terms and Conditions (the Legal Terms) form a legally binding agreement between you, whether personally or on behalf of a company, organisation or other legal entity (you), and AirPlus Renewables Ltd in relation to your access to and use of the Services.

By accessing or using the Services, submitting an enquiry, requesting a quotation, requesting distributor information, downloading information, purchasing products or engaging with us in relation to our products or services, you confirm that you have read, understood and agree to be bound by these Legal Terms.

If you do not agree with these Legal Terms, you must not use the Services.

Supplemental terms, proposals, quotations, order confirmations, distributor agreements, installation agreements, warranty documents, return policies, technical documents or other written terms may apply to specific products, projects, purchases or relationships. Where a specific written agreement has been agreed between you and us, that specific agreement will apply in addition to these Legal Terms. If there is a conflict between these Legal Terms and a specific written agreement signed or expressly accepted by both parties, the specific written agreement will take priority for that matter.

We may update these Legal Terms from time to time. We will indicate changes by updating the Last updated date above. Your continued use of the Services after updated Legal Terms are posted means that you accept the updated Legal Terms.

The Services are intended for users who are at least 18 years of age, or who are accessing the Services with the permission and supervision of a parent or legal guardian. The Services are primarily intended for business, commercial, industrial, public sector, distributor and professional enquiries.

You should print or save a copy of these Legal Terms for your records.

1. OUR SERVICES

AirPlus Renewables provides information about renewable energy technology, decentralised energy solutions and related products. This may include information about static wind, mobile wind, hydro technology, distributor opportunities, support services, technical data, case studies, news, enquiries, demonstrations, quotations, orders and related communications.

The Services may include information about products including, without limitation, XEVA, XKOROST and XYQUA, together with any successor products, product variations or related systems.

The Services are provided for general information, enquiry, communication and commercial engagement purposes. They do not constitute engineering advice, legal advice, planning advice, electrical advice, financial advice, investment advice, tax advice, grid connection advice or professional advice specific to your site or circumstances.

You must obtain appropriate professional advice before making decisions relating to installation, planning, building suitability, electrical connection, grid connection, health and safety, financial return, procurement, investment, compliance or use of any renewable energy product.

2. BUSINESS USE AND CONSUMER RIGHTS

The Services are primarily intended for business, commercial, industrial, public sector, distributor, installer and professional users.

If you use the Services on behalf of a business, company, organisation, public body, distributor, installer or other legal entity, you confirm that you have authority to bind that entity.

If you are a consumer, nothing in these Legal Terms limits any statutory rights that cannot legally be excluded.

Where we supply products or services to a business customer, those products and services may be subject to separate commercial terms, quotation terms, supply terms, installation terms, distributor terms, warranty terms or other written agreements.

3. INFORMATION ON THE SITE

We aim to keep information on the Site accurate, clear and up to date. However, information on the Site may occasionally contain errors, omissions, outdated information or indicative statements.

Images, graphics, animations, videos, diagrams, renders, product visuals and illustrations are provided for general presentation only. They may not represent exact dimensions, finishes, specifications, installation arrangements, production models or final product configurations.

Any information on the Site may be changed, corrected, updated, removed or replaced at any time without notice.

You should not rely solely on website information when making purchasing, investment, installation, planning, operational or technical decisions. Formal product specifications, written quotations, technical documents, site assessments and project specific agreements should be reviewed before any commitment is made.

4. PRODUCT INFORMATION AND TECHNICAL DATA

We make reasonable efforts to present product information, specifications, features, dimensions, performance data, materials, installation information and technical details accurately.

However, product information may be indicative, subject to development, testing, certification, manufacturing updates, supplier updates, regulatory requirements, product improvements, engineering changes or project specific design decisions.

Unless confirmed in a final written quotation, technical specification or signed agreement, product information on the Site should not be treated as a final specification or contractual commitment.

We reserve the right to change product specifications, product names, product designs, product availability, materials, finishes, components, software, control systems, monitoring systems, performance assumptions and technical documentation at any time where reasonably required.

Where a product is subject to certification, testing, regulatory approval, conformity assessment or manufacturing validation, any statements made before completion of those processes are indicative only unless expressly confirmed in writing.

5. PERFORMANCE ESTIMATES AND ENERGY OUTPUT

Any energy output figures, return on investment estimates, carbon saving estimates, cost saving estimates, payback period estimates, performance comparisons or similar statements are provided for general illustration only unless expressly confirmed in a project specific written agreement.

Actual performance may vary significantly depending on factors including:

• Site location
• Wind speed and wind consistency
• Wind direction and turbulence
• Mounting height
• Surrounding buildings, trees and obstructions
• Roof condition and structural suitability
• Installation method
• Electrical configuration
• Grid connection arrangements
• Battery or storage configuration
• Inverter and control systems
• Maintenance standards
• Weather conditions
• Local energy tariffs
• Export rates
• System downtime
• User behaviour
• Regulatory or network restrictions

We do not guarantee any specific energy output, financial saving, carbon saving, return on investment, payback period, export income, grid benefit or suitability for any particular site unless expressly stated in a signed written agreement.

Any comparison with solar panels, traditional wind turbines, grid electricity, diesel generation or other energy technologies is provided for illustrative purposes and should be checked against site specific data before reliance is placed on it.

6. SITE SUITABILITY, SURVEYS AND INSTALLATION REQUIREMENTS

A product may not be suitable for every property, roof, structure, site, environment or location.

Before installation, a suitable assessment may be required. This may include consideration of:

• Structural suitability
• Roof condition
• Mounting location
• Wind conditions
• Planning requirements
• Access requirements
• Electrical infrastructure
• Grid connection requirements
• Health and safety requirements
• Maintenance access
• Local environmental conditions
• Noise, vibration and neighbouring property considerations
• Insurance requirements
• Landlord, owner, freeholder or occupier consent

You are responsible for providing accurate site information, ownership information, access details, electrical information, structural information and any other details reasonably required to assess suitability.

Unless expressly agreed in writing, we are not responsible for structural surveys, planning assessments, grid applications, landlord consents, roof warranties, building control approvals, lease restrictions, insurance approvals or professional site advice.

Where a survey, feasibility assessment or technical review is carried out, it is based on the information available at the time and does not remove the need for any required specialist professional advice.

7. PLANNING, PERMISSIONS, GRID CONNECTION AND REGULATORY REQUIREMENTS

You are responsible for ensuring that all necessary permissions, approvals and consents are obtained before installing or using any product unless we expressly agree in writing to manage a specific part of that process.

This may include, where applicable:

• Planning permission
• Permitted development checks
• Building control approval
• Structural approval
• Landlord, owner or freeholder consent
• Leaseholder or tenant consent
• Insurance approval
• Grid connection approval
• Distribution Network Operator approval
• Electrical certification
• Health and safety documentation
• Environmental permissions
• Public sector or procurement approvals
• Import, export or local market approvals outside the United Kingdom

We do not guarantee that any product or installation will be approved by a planning authority, Distribution Network Operator, regulator, landlord, insurer, building control body, public authority or other third party.

Where products are placed on the market, conformity marking, product compliance and regulatory requirements may apply. Product compliance obligations may vary depending on product type, jurisdiction, market, intended use, installation method and supply chain role.

8. QUOTATIONS, ORDERS AND CONTRACT FORMATION

Any quotation, estimate, proposal, product information, website price or commercial discussion is subject to confirmation and does not form a binding contract unless accepted in accordance with our written process.

A binding contract may be formed when:

• We issue a written quotation or order confirmation
• You accept that quotation or order confirmation
• Any required deposit or payment is received
• We confirm acceptance of the order in writing

We reserve the right to refuse, cancel, amend or decline any order or enquiry where we reasonably consider it necessary. This may include where products are unavailable, information is inaccurate, pricing is incorrect, site suitability is uncertain, regulatory requirements cannot be met, payment is not received, fraud is suspected or the order creates an unacceptable legal, technical, financial, reputational or operational risk.

Any additional work, changes, site requirements, installation conditions, technical requirements, delivery requirements or regulatory requirements not included in the original quotation may be charged separately.

9. PURCHASES, PAYMENT AND PRICING

All prices are stated in GBP unless otherwise confirmed in writing.

Prices may be exclusive of VAT, delivery, installation, commissioning, surveys, structural assessments, grid connection works, electrical works, access equipment, scaffolding, lifting equipment, maintenance, monitoring, training, permits or other costs unless expressly stated otherwise.

You agree to provide current, complete and accurate purchase, billing, delivery and account information.

We may change prices at any time before a binding contract is formed. We reserve the right to correct pricing errors, typographical errors or quotation errors even if payment has been requested or received.

Where payment is required, you must pay all charges, deposits, stage payments, delivery fees, installation fees, taxes and other applicable amounts in accordance with the relevant quotation, invoice or written agreement.

We may suspend delivery, installation, commissioning, support, access to documents or further services where payment is overdue.

Ownership of physical products will not pass to you until full cleared payment has been received unless otherwise agreed in writing. Risk in products may pass in accordance with the relevant delivery, installation or supply terms.

10. DELIVERY, AVAILABILITY AND LEAD TIMES

All products are subject to availability.

Any delivery date, production date, installation date, commissioning date or lead time is an estimate unless expressly confirmed in writing as a fixed contractual deadline.

Delivery and installation may be affected by factors outside our reasonable control, including manufacturing schedules, component supply, certification processes, customs, transport issues, weather, site access, client delays, regulatory approvals, grid connection approvals, labour availability, third party contractors and force majeure events.

We are not responsible for delay caused by missing information, late payment, access restrictions, site issues, third party approvals, client actions or events outside our reasonable control.

11. RETURNS, CANCELLATIONS AND REFUNDS

Please review our Return Policy before making any purchase. Our Return Policy is available on the Services and may be updated from time to time.

Returns, cancellations and refunds may depend on whether you are a business customer or consumer, whether products are standard or bespoke, whether products have been installed, whether products have been used, whether products have been specially ordered and whether services have already been performed.

Products that are bespoke, customised, made to order, specially procured, installed, used, damaged, altered or supplied for a specific site may not be eligible for return unless faulty or unless required by law.

Nothing in these Legal Terms limits any statutory rights that cannot legally be excluded.

Where you believe a product is faulty, damaged or incorrectly supplied, you must notify us in writing as soon as reasonably possible and provide evidence of the issue.

12. INSTALLATION, COMMISSIONING AND HANDOVER

Installation and commissioning must be carried out by suitably competent persons and in accordance with applicable product instructions, technical documentation, electrical standards, health and safety requirements, site requirements and legal obligations.

Where we provide or arrange installation services, the scope of installation will be set out in the relevant quotation, proposal, order confirmation, installation agreement or written document.

Unless expressly included in writing, installation does not include structural works, roof repairs, scaffolding, lifting equipment, electrical upgrades, grid applications, planning applications, building control applications, making good, decoration, specialist access works, asbestos works, fire stopping, additional containment, civil works or unrelated site works.

You must ensure safe access, accurate site information, required permissions, suitable working conditions and cooperation from site staff, owners, landlords, occupiers and contractors.

We may refuse or delay installation where we reasonably consider the site unsafe, unsuitable, inaccessible, non compliant or materially different from the information provided.

13. DISTRIBUTORS, INSTALLERS AND THIRD PARTY PARTNERS

The Services may include opportunities to enquire about becoming a distributor, installer, partner or approved representative.

Submitting an enquiry does not guarantee approval, appointment, exclusivity, territory rights, pricing rights, supply rights, marketing rights, installation rights or any commercial relationship.

Any distributor, installer, partner or representative relationship must be confirmed in a separate written agreement.

We may work with third party distributors, installers, contractors, consultants, engineers or delivery partners. Unless expressly stated in writing, third parties are independent from us and are responsible for their own acts, omissions, advice, work, staff, insurance, licences, accreditations, compliance and customer relationships.

We are not responsible for unauthorised statements, promises, quotations, representations, guarantees or commitments made by third parties unless we have expressly approved them in writing.

14. PRODUCT WARRANTY AND MAINTENANCE

Any warranty that applies to a product will be set out in the applicable warranty document, quotation, order confirmation or written agreement.

Unless expressly stated in writing, warranty coverage does not include faults, damage or reduced performance caused by:

• Incorrect installation
• Unauthorised modification
• Misuse or neglect
• Failure to follow instructions
• Lack of maintenance
• Accident, vandalism or external impact
• Extreme weather beyond stated tolerances
• Unsuitable site conditions
• Electrical faults outside the product
• Grid issues or third party equipment
• Work carried out by unauthorised persons
• Use outside the stated purpose or specification

Routine inspection, servicing and maintenance may be required to maintain safety, performance and warranty coverage.

You are responsible for arranging ongoing maintenance unless we have expressly agreed to provide maintenance services in writing.

15. HEALTH, SAFETY AND PROPER USE

Renewable energy products, electrical systems, moving components, roof mounted systems, structural fixings and associated equipment can involve risk if installed, accessed, maintained or used incorrectly.

You must follow all safety instructions, manuals, warning notices, maintenance requirements and legal obligations applicable to the product and installation.

You must not allow unauthorised, unqualified or unsuitable persons to install, repair, modify, access, dismantle or interfere with products or associated systems.

You must notify us promptly if you become aware of any safety issue, fault, abnormal noise, vibration, damage, reduced performance, suspected defect or misuse.

16. INTELLECTUAL PROPERTY RIGHTS

We are the owner or licensee of all intellectual property rights in the Services, including the Site, software, databases, functionality, website designs, audio, video, text, photographs, graphics, product names, product descriptions, technical content, diagrams, documents, downloads, trade marks, service marks, logos and branding (the Content and Marks).

The Content and Marks are protected by copyright, trade mark, design right, database right, confidential information rights and other intellectual property laws.

The Content and Marks are provided through the Services for your personal, internal business or evaluation purposes only.

Subject to your compliance with these Legal Terms, we grant you a limited, non exclusive, non transferable, revocable licence to access the Services and download or print materials made available by us solely for your legitimate personal or internal business evaluation use.

You must not copy, reproduce, republish, upload, post, publicly display, encode, translate, transmit, distribute, sell, license, commercially exploit, reverse engineer, imitate or create derivative works from any part of the Services, Content or Marks without our prior written permission.

You must not use our Content, Marks, product names, technical materials, diagrams, documents or branding to suggest approval, distribution rights, agency, partnership, reseller rights, installation rights or affiliation without our written permission.

We reserve all rights not expressly granted to you.

17. USER REPRESENTATIONS

By using the Services, you represent and warrant that:

• You have the legal capacity and authority to agree to these Legal Terms
• Any information you provide is accurate, complete and not misleading
• You will keep information provided to us up to date where relevant
• You will not use the Services for any unlawful or unauthorised purpose
• You will not use the Services in a way that violates any applicable law or regulation
• You will not access the Services through automated or non human means without our written permission
• If acting for a business or organisation, you have authority to act on its behalf

If you provide information that is untrue, inaccurate, incomplete or misleading, we may suspend or refuse access to the Services, decline enquiries, cancel orders or terminate the relevant relationship where appropriate.

18. PROHIBITED ACTIVITIES

You may not access or use the Services for any purpose other than the purpose for which we make them available.

You agree not to:

• Systematically retrieve, scrape, copy or compile data, content or technical information from the Services without written permission
• Circumvent, disable or interfere with security related features of the Services
• Use the Services to mislead, defraud, impersonate or harm another person or organisation
• Upload or transmit viruses, malware, spyware or harmful code
• Interfere with, disrupt or place an unreasonable burden on the Services or connected systems
• Use bots, scrapers, spiders, scripts, offline readers or automated tools without written permission
• Delete copyright, trade mark or proprietary rights notices from Content
• Copy, adapt, decompile, disassemble or reverse engineer any software or code forming part of the Services except where permitted by law
• Use the Services, Content or Marks to compete with us or develop competing products, services, marketing materials or technical materials
• Collect email addresses, contact details or user information for unsolicited marketing
• Make unauthorised statements suggesting that you are approved, appointed, endorsed or authorised by us
• Use the Services to advertise or sell goods or services without our written approval
• Use the Services in breach of any applicable law, regulation or third party right

19. USER SUBMISSIONS AND CONTRIBUTIONS

You may send us enquiries, questions, comments, suggestions, ideas, feedback, documents, site information, technical information, images, drawings, specifications or other materials (together, Submissions).

By sending Submissions to us, you confirm that:

• You have the right to send them to us
• They are accurate and not misleading where factual
• They do not infringe third party rights
• They do not contain unlawful, confidential or restricted information unless you are authorised to share it
• We may use them to respond to your enquiry, assess suitability, prepare quotations, provide support, improve the Services and communicate with you

You remain responsible for your Submissions.

If you provide feedback, suggestions or ideas relating to our products, Services, marketing, functionality or business, you agree that we may use them without restriction, payment or obligation to you unless expressly agreed in writing.

20. THIRD PARTY WEBSITES, TOOLS AND CONTENT

The Services may include links to third party websites, tools, documents, platforms, mapping services, payment providers, finance providers, installers, distributors, certification bodies, regulators, manufacturers, software providers or other third party content.

Third party websites, tools and content are not controlled by us. We are not responsible for their content, accuracy, availability, security, privacy practices, policies, fees, decisions or performance.

Your use of third party websites, tools and services is subject to their own terms and policies.

21. PRIVACY POLICY

We care about privacy and data protection. Please review our Privacy Policy at:

https://airplusrenewables.com/privacy-policy.htm

By using the Services, you acknowledge that your personal data will be handled in accordance with our Privacy Policy.

Where we receive business contact details, enquiry details, site information or project information, we may use this information to respond to enquiries, assess requirements, communicate with you and provide the Services as further described in our Privacy Policy.

22. SERVICES MANAGEMENT

We reserve the right, but not the obligation, to:

Monitor the Services for breaches of these Legal Terms

Take appropriate action where the Services are misused

Restrict, suspend or block access where reasonably necessary

Remove or disable content that is unlawful, harmful, excessive, inaccurate, infringing or burdensome to our systems

Manage the Services to protect our rights, users, systems, products and business

23. TERM, SUSPENSION AND TERMINATION

These Legal Terms remain in force while you use the Services.

We may suspend, restrict or terminate your access to the Services where we reasonably believe that:

You have breached these Legal Terms

You have misused the Services

You have provided false, inaccurate or misleading information

Your use creates a legal, technical, financial, reputational, security or operational risk

We are required to do so by law, regulator, court order or competent authority

We may also take legal action where appropriate.

24. MODIFICATIONS, INTERRUPTIONS AND CORRECTIONS

We may change, modify, update, suspend, withdraw or discontinue any part of the Services at any time.

We cannot guarantee that the Services will always be available, uninterrupted, secure, error free or compatible with every device, browser or system.

We may experience hardware, software, hosting, maintenance, cyber security, supplier or third party issues that cause interruptions, delays or errors.

There may be typographical errors, inaccuracies or omissions on the Services, including descriptions, technical information, pricing, availability, lead times and other information. We reserve the right to correct any errors, inaccuracies or omissions at any time without prior notice.

25. DISCLAIMER

The Services are provided on an as available basis.

To the fullest extent permitted by law, we make no warranty that the Services, Site content, product information, performance statements, technical information, savings estimates, return on investment estimates, availability information, third party links or other materials will be complete, accurate, current, uninterrupted or error free.

Nothing on the Site should be treated as professional engineering advice, financial advice, investment advice, legal advice, planning advice, building advice, electrical advice, grid connection advice, insurance advice or site specific advice.

You should obtain appropriate professional advice before making decisions based on the Services.

26. LIMITATIONS OF LIABILITY

Nothing in these Legal Terms excludes or limits liability where it would be unlawful to do so. This includes liability for death or personal injury caused by negligence, fraud, fraudulent misrepresentation and any liability that cannot legally be excluded or limited.

Subject to the above, we will not be liable for:

• Loss of profit, revenue, business, contracts, opportunity, goodwill, reputation, anticipated savings or data
• Indirect or consequential loss
• Loss caused by reliance on website information that has not been confirmed in a written project specific agreement
• Loss caused by performance estimates, savings estimates, carbon estimates, payback estimates or return on investment estimates
• Loss caused by site unsuitability, planning refusal, grid connection refusal, landlord refusal, insurer refusal, access issues or structural issues
• Loss caused by installation, maintenance, advice, promises, statements or omissions of independent third party installers, distributors, contractors or partners
• Loss caused by misuse, unauthorised modification, unsuitable installation, lack of maintenance or failure to follow instructions
• Loss caused by third party websites, tools, systems, suppliers, components, installers, consultants, authorities or service providers
• Loss caused by delay or failure arising from events outside our reasonable control
• Loss caused by use of products outside their stated specification, purpose, documentation or safety instructions

If you are a consumer, we are responsible for foreseeable loss and damage caused by our breach of these Legal Terms or our failure to use reasonable care and skill. We are not responsible for loss or damage that is not foreseeable.

Where you are using the Services for business or commercial purposes, and where we are legally permitted to limit liability, our total liability for claims relating to the Services will not exceed the amount paid by you to us for the specific product or service giving rise to the claim.

If no amount was paid for the relevant Service, our total liability will be limited to £100 to the fullest extent permitted by law.

27. INDEMNIFICATION

You agree to indemnify and hold us harmless, including our officers, directors, employees, contractors, consultants, suppliers, affiliates and partners, from and against claims, losses, damages, liabilities, costs and expenses arising from:

• Your use or misuse of the Services
• Your breach of these Legal Terms
• Any inaccurate, incomplete or misleading information you provide
• Your breach of third party rights
• Your failure to obtain required permissions, approvals, consents, licences or professional advice
• Your unauthorised use of our Content, Marks, product names, documents or technical materials
• Your unauthorised statements, representations, promises or commitments relating to us or our products
• Any installation, modification, maintenance or use carried out contrary to our instructions, documentation or written requirements

This indemnity applies to the fullest extent permitted by law.

28. USER DATA

We may maintain certain data that you transmit to the Services for the purpose of managing the Services, responding to enquiries, preparing quotations, supporting projects, improving performance and maintaining records.

Although we may carry out routine system management and use reasonable measures to protect information, you are responsible for retaining copies of information, documents and materials you provide to us.

We are not responsible for loss or corruption of data caused by events outside our reasonable control, third party systems, user error or unauthorised access not caused by our proven negligence.

29. ELECTRONIC COMMUNICATIONS

Visiting the Services, sending us emails, submitting online forms and communicating with us electronically constitute electronic communications.

You consent to receive electronic communications from us. You agree that agreements, notices, disclosures, quotations, updates and other communications we provide electronically satisfy any legal requirement that such communications be in writing, unless the law requires another form.

30. CONFIDENTIALITY

If either party shares confidential business, technical, commercial or project information, the receiving party must keep that information confidential and use it only for the purpose for which it was provided.

Confidential information does not include information that is public, already known, independently developed or lawfully received from another source.

This clause does not prevent disclosure where required by law, regulator, court order, professional adviser or competent authority.

31. EXPORT, INTERNATIONAL USE AND SANCTIONS

The Services are operated from the United Kingdom.

We do not guarantee that the Services, products, documentation or information are appropriate or available in every country or territory.

If you access the Services from outside the United Kingdom or enquire about international supply, distribution, installation or use, you are responsible for complying with applicable local laws, import rules, export rules, product standards, tax rules, customs requirements, sanctions laws, planning rules, electrical standards and regulatory requirements.

We may refuse to provide products, Services, information, support, distribution rights or commercial engagement where we reasonably believe doing so may breach legal, regulatory, sanctions, export control, technical, safety, reputational or operational requirements.

32. GOVERNING LAW AND JURISDICTION

These Legal Terms are governed by the laws of England and Wales.

If you are a business customer, the courts of England and Wales will have exclusive jurisdiction over any dispute relating to these Legal Terms or the Services.

If you are a consumer living in the United Kingdom, you may bring legal proceedings in the courts of England and Wales. If you live in Scotland or Northern Ireland, you may also bring proceedings in your local courts.

If you are a consumer living outside the United Kingdom, you may have additional rights under the mandatory laws of the country where you live.

33. DISPUTE RESOLUTION

Before starting formal proceedings, the parties will use reasonable efforts to resolve any dispute through written communication.

Either party may send written notice of a dispute to the other party. The parties will then attempt to resolve the dispute in good faith for at least 30 days, unless urgent action is required.

Nothing in this section prevents either party from seeking urgent injunctive relief, protecting intellectual property rights, preventing misuse of confidential information, recovering unpaid sums or taking action where delay would cause serious harm.

34. MISCELLANEOUS

These Legal Terms and any policies or written terms posted by us on the Services or agreed with you constitute the entire agreement between you and us in relation to your use of the Services, except where a separate written agreement applies.

Our failure to enforce any right or provision of these Legal Terms does not operate as a waiver of that right or provision.

We may assign or transfer our rights and obligations under these Legal Terms where reasonably required, provided this does not materially reduce your legal rights.

We will not be responsible for delay or failure caused by events outside our reasonable control.

If any provision or part provision of these Legal Terms is found to be unlawful, void or unenforceable, that provision or part provision will be treated as removed to the minimum extent necessary. The remaining provisions will continue in full force.

No joint venture, partnership, employment, agency, distributor, reseller or representative relationship is created by your use of the Services unless confirmed in a separate written agreement.

35. CONTACT US

To resolve a complaint regarding the Services or to receive further information about use of the Services, please contact us at:

• Email: info@airplusrenewables.com
• Website: https://airplusrenewables.com